Are You Sure?

LEGAL NOTICE Sealed proposals will be received by the Worth Township of Butler County at 815 West Park Road, Slippery Rock, PA 16057 until 4:00 P.M., on June 2, 2026, for the following: ITEM 1 - 540 Tons 1B Limestone ITEM 2 - 500 Tons 2A ITEM 3 - 150 Tons R-4 ITEM 4 - 150 Tons #9 Quote Pick up and Delivered Prices Liquidated Damages Apply $975.00 per calendar day. Proposals must be upon the forms furnished by the Municipality. The bid must be accompanied by a certified check or bid bond in the amount of 10% of the bid, made payable to the municipality. The Municipality reserves the right to reject any or all proposals. Worth Township BY: Shari Kreutz Secretary/Treasurer May 5, 2026

ESTATE NOTICE Estate of CLAIR T. UBER, Late of 231 Freeport Road, Butler, Butler County, Pennsylvania, deceased. Letters Testamentary upon the above-named estate having been granted to the undersigned, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to: JACK UBER, Executor 1744 New Bedford Sharon Road West Middlesex, PA 16159 Andrea C. Parenti, Esquire DILLON McCANDLESS KING COULTER & GRAHAM LLP 128 West Cunningham Street Butler, PA 16001 724-283-2200

EXECUTORS NOTICE Estate of PATRICIA E. TUBRIDY, Late of Zelienople, Butler County, Pennsylvania, deceased. Letters testamentary upon the above-named estate having been granted to the undersigned, at Estate File No. 10-26-0514, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to: SHERRI L. TUBRIDY, Executor 336 Ridge Road Zelienople, PA 16063

LEGAL NOTICE Sealed proposals will be received by the Fairview Township of Butler County at 1571 Hooker Road, Karns City 16041 until 6:00 P.M., on June 8, 2026, for the following: ITEM 1 - 8,921 S.Y. - BASE REPAIRS, IN PLACE Note: Prevailing wage rates shall apply to this contract. Liquidated damages apply at the rate of $975.00 per calendar day. Proposals must be upon the forms furnished by the Municipality. For third class cities the bid must be accompanied by a certified check or bid bond in the amount of 10% of the bid, made payable to the municipality. For other municipal types it is the discretion of the municipality. A performance bond or certified check in the amount of 100% of the contract shall be furnished by the successful bidder within 20 days after the contract is awarded. The Municipality reserves the right to reject any or all proposals. Fairview Township BY: Dusty Dudzic Secretary/Treasurer

LEGAL NOTICE Sealed proposals will be received by the Worth Township of Butler County at 815 West Park Road, Slippery Rock, PA 16057 until 4:00 P.M., on June 2, 2026, for the following: ITEM 1 - 54,000 Gallons CRS2/POLYMER APPLIED ITEM 2 - 2,500 Gallons MC70 APPLIED Liquidated damages apply $975.00 per calendar day. Proposals must be upon the forms furnished by the Municipality. The bid must be accompanied by a certified check or bid bond in the amount of 10% of the bid, made payable to the municipality. The Municipality reserves the right to reject any or all proposals. Worth Township, Butler County BY: Shari Kreutz Secretary/Treasurer May 6, 2026

LEGAL NOTICE Sealed proposals will be received by the Slippery Rock Municipal Authority, Butler County at 116 Crestview Road or PO Box 157, Slippery Rock, PA 16057, until 5:15 P.M. on June 10, 2026, for the following: Milling of Asphalt, Base Repairs, and Asphalt Wearing Course 9.5mm for 3,668 sq ft trench, or as needed on Elm Street, Slippery Rock, PA 16057. Proposals must be on the forms furnished by the Authority. The Authority reserves the right to reject any/or all proposals. Heather Sholes, Executive Administrator

LEGAL NOTICE FICTITIOUS NAME NOTICE IS HEREBY GIVEN, pursuant to the provisions of Act of Assembly No.295, effective March 16, 1983, as amended, of intention to file in the office of the Department of State of the Commonwealth of Pennsylvania, Harrisburg, Pennsylvania on the 14th day of May, 2026 an application for the conduct of a business in Butler County, Pennsylvania, under the assumed or fictitious name, style or designation of: STEEL CITY TUNNEL PARTNERS with its principal place of business at 1000 John Roebling Way, Saxonburg, PA 16056. The name(s) and address(es) of the person(s) owning or interested in said business is (are): Brayman Construction Corporation, 1000 John Roebling Way, Saxonburg, PA 16056; The Lane Construction Corporation, 90 Field-stone Court, Cheshire, CT 06410-1212 Attorney: Mark A. Savannah, Esquire 1000 John Roebling Way Saxonburg, PA 16056

LEGAL NOTICE IN THE COURT OF COMMON PLEAS OF BUTLER COUNTY, PENNSYLVANIA NOTICE OF FILING OF PETITION FOR NAME CHANGE In the Matter of MsD. No. 2026-40034 Notice is hereby given that, on February 10th, 2026, the petition of Name Change was filed in the above-named court, requesting an order to change the name of TYLER NICHOLAS EGAN to SAMANTHA ZARA EGAN. The Court has fixed the 23rd day of June, 2026, at 9:45 A.M. in Court Room number 3, Court House, Butler, Pennsylvania as the time and place for the hearing on said petition, when and where all interested parties may appear and show cause, if any, why the request of the petitioner should not be granted.

LEGAL NOTICE Sealed proposals will be received by the Slippery Rock Municipal Authority, Butler County at 116 Crestview Road or PO Box 157, Slippery Rock, PA 16057, until 5:15 P.M. on June 10, 2026, for the following: Quantity 1,000 Unit Tons, Description #2A limestone delivered to Elm Street, Slippery Rock, PA 16057, as needed. Proposals must be on the forms furnished by the Authority. The Authority reserves the right to reject any/or all proposals. Heather Sholes, Executive Administrator

ESTATE NOTICE Estate of MARGARET J. SWIGART, Late of Fairview Township, Butler County, Pennsylvania, deceased. Letters of Administration D.B.N. C.T.A. upon the above-named Estate having been granted to the undersigned at Estate File No. 10-24-0864, and all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to: Andrea Lyn Boyle, Esquire c/o LUTZ PAWK & BLACK The NexTier Center Building, Suite 102 101 East Diamond Street Butler, PA 16001

LEGAL NOTICE Notice is hereby given that a Joint Operating Committee Personnel Subcommittee Meeting will be held at 9:00 A.M., Friday, May 22, 2026, in the Butler County AVTS Directors Office, 210 Campus Lane, Butler, PA 16001. Mr. Mark Taylor Joint Operating Committee Secretary

LEGAL NOTICE OF PUBLIC SALE Lock Solid Storage is selling property to satisfy a landlords lien for nonpayment of rent. Sale to be held online at Bid13.com. Facility located at 101 Clearview Circle Butler, PA 16001. Auction Bidding will close on or after June 22nd 2026 at 10:00 A.M. Cleanup deposit is required. Seller reserves the right to withdraw the property at any time before the sale. Unit items sold as-is to the highest bidder. Property includes the contents of spaces of the following tenant(s): All spaces contain household items unless noted. Bobbi Sue Jones-Unit 104 Alexis Boyd - Unit 107 Kevin Stoner - Unit 144 (5-26, 6-2-26)

EXECUTRIXS NOTICE Estate of KAREN A. TREMPUS, Late of Saxonburg, Butler County, Pennsylvania, deceased. Letters testamentary upon the above-named estate having been granted to the undersigned, at Estate File No. 10-26-0548, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to: MARJORIE J. ZELLHART, Executrix c/o 210 Fifth Avenue Tarentum, PA 15084 CHARLES T. CLARK, Esquire 210 Fifth Avenue Tarentum, PA 15084

LEGAL NOTICE EMLENTON BOROUGH ORDINANCE Notice is hereby given that the Council for the Borough of Emlenton will vote to amend Section 4.B of the Nuisance Ordinance of the Borough of Emlenton, Venango County, Pennsylvania (Ordinance #390) at its meeting held at 6:00 P.M. on Monday, June 1, 2026, at the Borough Hall, 511 Hill Street, Emlenton, PA 16373. Proposed Amendment- Section 4.B - Containers The owner or operator of every establishment producing or disposing of trash, garbage, vegetable waste, or recyclable material shall, at all times, utilize an approved container with a close-fitting cover for storage until removal from the premises. Containers shall be maintained in a sanitary condition and shall not emit offensive odors detectable beyond the property line and shall otherwise be maintained so as not to constitute a Nuisance as defined in Section 1 of this Ordinance. Notwithstanding any other provision of this Ordinance relating to notice or time for correction, violations of this Section that result in insect or rodent infestation, maggots or vermin, leakage of putrescible materials, or offensive odors detectable beyond the property line are declared to constitute conditions affecting public health requiring immediate correction upon notice from the Borough, and routine or scheduled emptying shall not be deemed correction or abatement unless full compliance with this Section is achieved. Each day such a violation continues shall constitute a separate offense. All other terms and provisions of the Nuisance Ordinance of the Borough of Emlenton (Ordinance #390), as previously enacted and amended, shall remain in full force and effect except as amended hereby.

LEGAL NOTICE IN THE COURT OF COMMON PLEAS OF BUTLER COUNTY, PENNSYLVANIA NOTICE OF FILING OF PETITION FOR NAME CHANGE In the Matter of MsD. No. 2026-40034 Notice is hereby given that, on February 10th, 2026, the petition of Name Change was filed in the above-named court, requesting an order to change the name of TYLER NICHOLAS EGAN to SAMANTHA ZARA EGAN. The Court has fixed the 23rd day of June, 2026, at 9:45 A.M. in Court Room number 3, Court House, Butler, Pennsylvania as the time and place for the hearing on said petition, when and where all interested parties may appear and show cause, if any, why the request of the petitioner should not be granted.

LEGAL NOTICE IN THE COURT OF COMMON PLEAS OF BUTLER COUNTY, PENNSYLVANIA NOTICE OF FILING OF PETITION FOR CHANGE OF NAME In the Matter of MsD. No. 2026-40104 Notice is hereby given that, on April 8, 2026, a Petition for Change of Name was filed in the above-named Court, requesting an order to change the name of BARBARA KYLE CLEELAND to KYLE CLEELAND PORTER. The Court has fixed the 23rd day of June, 2026, at 9:45 A.M. in Courtroom Number 3 of the Butler County Government Center as the time and place for the hearing on said petition, when and where all interested parties may appear and show cause, if any, why the request of the Petitioner should not be granted.

LEGAL NOTICE OF PUBLIC SALE Lock Solid Storage is selling property to satisfy a landlords lien for nonpayment of rent. Sale to be held online at Bid13.com. Facility located at 112 Hillvue Drive Butler, PA 16001. Auction Bidding will close on or after June 22nd 2026 at 10:00 A.M. Cleanup deposit is required. Seller reserves the right to withdraw the property at any time before the sale. Unit items sold as-is to the highest bidder. Property includes the contents of spaces of the following tenant(s): All spaces contain household items unless noted. Evan Winter - Unit B19 Emaleigh Freeman - Unit B30 (5-26, 6-2-26)

LEGAL NOTICE PUBLIC AUCTION May 26, 2026 at 9:00 A.M. AT BOFFS AUTO SERVICE, 323 Warrendale Road, Wexford, PA 15090 2013 Ford SW 1FADP5AU2DL512820 Right to cancel the sale is reserved.

LEGAL NOTICE Sealed proposals will be received by the Chicora Borough of Butler County at PO Box J, 110 Firehouse Cart-way, Chicora, PA 16025 until 1:00 P.M., on June 8, 2026, for the following: ITEM 1 - 9,189 S.Y. - SINGLE ASPHALT SEAL COAT, IN PLACE ITEM 2 - 1,415 S.Y. - ASPHALT FOG SEAL FOR ASPHALT SEAL COATS ITEM 3 - 2,489 S.Y. - DOUBLE ASPHALT SEAL COAT, IN PLACE ITEM 4 - 810 S.Y. - SINGLE ASPHALT SEAL COAT, IN PLACE, Parking Lot ITEM 5 - 810 S.Y. - ASPHALT FOG SEAL FOR ASPHALT SEAL COATS, Parking Lot Liquidated damages apply at the rate of $975.00 per calendar day. Proposals must be upon the forms furnished by the Municipality. For third class cities the bid must be accompanied by a certified check or bid bond in the amount of 10% of the bid, made payable to the municipality. For other municipal types it is the discretion of the municipality. A performance bond or certified check in the amount of 100% of the contract shall be furnished by the successful bidder within 20 days after the contract is awarded. The Municipality reserves the right to reject any or all proposals. Chicora Borough BY: Joanna Fair Secretary/Treasurer May 18, 2026

LEGAL NOTICE Sealed proposals will be received by the Chicora Borough of Butler County at PO Box J, 110 Firehouse Cart-way, Chicora, PA 16025 until 1:00 P.M., on June 8, 2026, for the following: ITEM 1 - 3,997 S.Y. - MILLING OF ASPHALT ITEM 2 - 136 TON - ASPHALT BINDER COURSE, 19.0mm, IN PLACE ITEM 3 - 278 TON - ASPHALT WEARING COURSE, 9.5mm, IN PLACE Liquidated damages apply at the rate of $975.00 per calendar day. Proposals must be upon the forms furnished by the Municipality. For third class cities the bid must be accompanied by a certified check or bid bond in the amount of 10% of the bid, made payable to the municipality. For other municipal types it is the discretion of the municipality. A performance bond or certified check in the amount of 100% of the contract shall be furnished by the successful bidder within 20 days after the contract is awarded. The Municipality reserves the right to reject any or all proposals. Chicora Borough BY: Joanna Fair Secretary/Treasurer May 18, 2026

EXECUTORS NOTICE Estate of MURIEL M. IVANCIK, Late of Sarver, Butler County, Pennsylvania, deceased. Letters testamentary upon the above-named estate having been granted to the undersigned, at Estate File No. 10-26-0484, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to: PAUL E. IVANCIK, Executor 111 Mar Vel Drive Butler, PA 16001

LEGAL NOTICE Notice is hereby given that Three Rivers Aggregates, LLC, 321 Currie Road, Slippery Rock, PA 16057, is requesting a stage II bond release from the Pennsylvania Department of Environmental Protection for the surface mine permit No.10180305-02, issued January 11, 2021, known as the Pfahl Mine. This permit is located in Worth Township, Butler County approximately five miles southwest of Slippery Rock, PA. More specifically, the proposed bond release area is located on the south side of Brandon Road, approximately one-half mile west of the intersection of I-79. The bond release area is located on the property of James C. and Katherine S. Pfahl. A Stage II bond release is reques-ted for SMP #10180305 for 17.3 acres. The area proposed for bond release has been backfilled, graded, topsoil replaced, and vegetation established which meets the specifications of the approved permit. The amount of bond presently in effect is $8,836.21, with the amount requested to be released being $8,836.21. The application, plans and other data concerning this operation for which bond release is requested are available for public inspection at the Bureau of Surface Mining and Reclamation, Pennsylvania Department of Environmental Protection, White Memorial Building, P.O. Box 669, Knox, PA 16232 between the hours of 8:00 A.M. and 4:00 P.M., Monday through Friday. Any such person who desires to object, request for informal conferences or public hearings or any written comments should write to the PA Department of Environmental Protection, Bureau of Surface Mining and Reclamation at the above address. The objection must include the persons name, address, telephone number and a brief statement as to the nature of his or her objection. The objections and/or comments should reply within thirty (30) days following the final (4th) publication.

LEGAL NOTICE The elected officials of Mars Borough and Adams Township will be holding a public informational meeting to discuss the potential merger betwe-en the two municipalities. The meeting will be held June 2, 2026 at Twelve Oaks Mansion, 160 Sch-arberry Lane, Mars, PA 16046 at 6:00 P.M. Residents and taxpayers are encouraged to attend. Please RSVP in advance at adamstwp.org.

LEGAL NOTICE EMLENTON BOROUGH ORDINANCE Notice is hereby given that the Council for the Borough of Emlenton will vote to amend Section 4.B of the Nuisance Ordinance of the Borough of Emlenton, Venango County, Pennsylvania (Ordinance #390) at its meeting held at 6:00 P.M. on Monday, June 1, 2026, at the Borough Hall, 511 Hill Street, Emlenton, PA 16373. Proposed Amendment- Section 4.B - Containers The owner or operator of every establishment producing or disposing of trash, garbage, vegetable waste, or recyclable material shall, at all times, utilize an approved container with a close-fitting cover for storage until removal from the premises. Containers shall be maintained in a sanitary condition and shall not emit offensive odors detectable beyond the property line and shall otherwise be maintained so as not to constitute a Nuisance as defined in Section 1 of this Ordinance. Notwithstanding any other provision of this Ordinance relating to notice or time for correction, violations of this Section that result in insect or rodent infestation, maggots or vermin, leakage of putrescible materials, or offensive odors detectable beyond the property line are declared to constitute conditions affecting public health requiring immediate correction upon notice from the Borough, and routine or scheduled emptying shall not be deemed correction or abatement unless full compliance with this Section is achieved. Each day such a violation continues shall constitute a separate offense. All other terms and provisions of the Nuisance Ordinance of the Borough of Emlenton (Ordinance #390), as previously enacted and amended, shall remain in full force and effect except as amended hereby.

LEGAL NOTICE OF PUBLIC SALE Lock Solid Storage is selling property to satisfy a landlords lien for nonpayment of rent. Sale to be held online at Bid13.com. Facility located at 118 South Main Street, Butler, PA 16001. Auction Bidding will close on or after June 22nd 2026 at 10:00 A.M. Cleanup deposit is required. Seller reserves the right to withdraw the property at any time before the sale. Unit items sold as-is to the highest bidder. Property includes the contents of spaces of the following tenant(s): All spaces contain household items unless noted. Stevona Morgan-Unit 53 Jordan Johnson-Unit 69 (5-26, 6-2-26)

LEGAL BID NOTICE The Butler County Airport Authority will receive proposals for Contract 2026-2, Pittsburgh-Butler Regional Airport, 473 Airport Road, Butler, PA 16002 until 11:00 A.M. local time on June 9th, 2026, which proposals will immediately there-after be publicly opened and read aloud. Contract No. 2026-2 Maintenance Building Plans, Specifications, and Proposals in Portable Document Format (PDF) may be down-loaded for free as outlined below. Contract Documents including Plans, Specifications Proposals, and addendums (if issued) will be available for examination and downloading beginning on May 19th, 2026 at the following website: http://bidportal.mjinc.com under the Project Name: Pittsburgh-Butler Regional Airport Contract No. 2026-2 - Maintenance Building Addendums and other additional or revised Contract Documents will be available on the website ONLY and it is the Bidders sole responsibility to check the website for additions or revisions up to the day prior to the due date for Proposals listed above. Addendums and other additional or revised Contract Documents will not be transmitted directly to Bidders or Plan Holders. There are separate contracts for General Construction, Electrical Construction, Plumbing Construction and HVAC Construction per the summary of work in specifications section 011200 MULTIPLE CONTRACT SUMMARY and the bid forms included in Section P-PROPOSAL. Bidders can submit on more than one contract. Questions regarding the technical aspects of the bid drawings and/or the contract documents should be directed to the Project Engineer. The Project Engineer is Nicholas Barber and can be contacted by email or phone at nbarber@mjinc.com or 814-594-0240. Bids shall be on the prescribed forms furnished by the Butler County Airport Authority and shall be in accordance with the General Provisions, Proposal Require-ments and Conditions Section 20. The Butler County Airport Authority expressly reserves the right to accept or reject any or all bids or to waive informalities in the same. Each bidder must deposit with this proposal a guarantee in an amount equal to at least ten percent (10%) of his bid. The Bid Guarantee shall consist of a firm commitment such as a bid bond, certified check, or other negotiable instrument accompanying a bid as assurance that the bidder will, upon acceptance of his bid, execute such contractual documents as may be required within the time specified. No bidder may withdraw his bid within one hundred twenty (120) days after the actual date of the opening thereof. Work shall be commenced within ten (10) days of the date specified in the written notification to proceed and shall be fully and finally completed within 180 Calendar days of the date specified in the written notification to proceed. The Butler Cou-nty Airport Authority hereby notifies that it will affirmatively ensure compliance with the regulations relative to nondiscrimination in Federally assisted programs of the Department of Transportation, title 49, Code of Federal Regu-lations, Part 26 (as they may be amended from time to time). A pre-bid meeting will be held on June 1st, 2026, at 11:00 A.M. at the Airport Terminal (Pittsburgh-Bulter Regional Airport, 473 Airport Road, Butler, PA 16002.) In accordance with 49 CFR Part 26, the DBE Goal for this contract is set at 0%. Bidders are encouraged to seek and obtain DBE participation. All DBE firms used to meet this goal must be certified by the PA UCP. Certification as a DBE by the PA UCP is separate and distinct from other certification programs. The only source that should be used for verification of current eligibility of a DBE firm is the PA UCP website as www.paucp .com. Physical certification letters and/or expiration dates should not be requested from DBE firms. All bidders are requested to submit a list of all firms that provide them quotes with the following information: a) Name of firm b) Address and telephone number of firm c) DBE status/category (if any) d) Age of firm e) Approximate annual gross receipts of business f) Type of work g) Dollar amount of work quoted The contractor or subcontractor, by submission of an offer and/or execution of a contract, certifies that it: a) is not owned or controlled by one or more citizens or nationals of a foreign country included in the list of countries that discriminate against U.S. firms published by the Office of the United States Trade Representative (USTR); b) has not knowingly entered into any contract or subcontract for this project with a contractor that is a citizen or national of a foreign country on said list, or is owned or controlled directly or indirectly by one or more citizens or nationals of a foreign country on said list; c) has not procured any product not subcontracted for the supply of any product for use on the project that is produced in a foreign country on said list. Successful bidder must enter into the Agreement and furnish a Contract bond and evidence of required insurance within fifteen (15) days after the notification of acceptance of such proposal, all as more specifically required in the Contract Documents. Wages as predetermined by the PA Department of Labor & Industry included in specifications and contract documents and/or addenda thereto shall be used by the contractor in paying labor in connection with the work under this contract. All work under this contract shall be under and subject to the regulations contained in Section R of the Contract Documents.

LEGAL NOTICE OF PUBLIC SALE Lock Solid Storage is selling property to satisfy a landlords lien for nonpayment of rent. Sale to be held online at Bid13.com. Facility located at 101 Clearview Circle Butler, PA 16001. Auction Bidding will close on or after June 22nd 2026 at 10:00 A.M. Cleanup deposit is required. Seller reserves the right to withdraw the property at any time before the sale. Unit items sold as-is to the highest bidder. Property includes the contents of spaces of the following tenant(s): All spaces contain household items unless noted. Bobbi Sue Jones-Unit 104 Alexis Boyd - Unit 107 Kevin Stoner - Unit 144 (5-26, 6-2-26)

LEGAL NOTICE FICTITIOUS NAME NOTICE IS HEREBY GIVEN, pursuant to the provisions of Act of Assembly No.295, effective March 16, 1983, as amended, of intention to file in the office of the Department of State of the Commonwealth of Pennsylvania, Harrisburg, Pennsylvania on the 14th day of May, 2026 an application for the conduct of a business in Butler County, Pennsylvania, under the assumed or fictitious name, style or designation of: STEEL CITY TUNNEL PARTNERS with its principal place of business at 1000 John Roebling Way, Saxonburg, PA 16056. The name(s) and address(es) of the person(s) owning or interested in said business is (are): Brayman Construction Corporation, 1000 John Roebling Way, Saxonburg, PA 16056; The Lane Construction Corporation, 90 Field-stone Court, Cheshire, CT 06410-1212 Attorney: Mark A. Savannah, Esquire 1000 John Roebling Way Saxonburg, PA 16056