Are You Sure?

LEGAL NOTICE¶ Sealed proposals will be received by the BRADY’S BEND TOWNSHIP of Armstrong County at 1004 State Route 68, East Brady, PA 16028 until 1:00 P.M., on May 4, 2026, for the following: ITEM 1 - 1200 feet installation of 6“ perf coiled pipeITEM 2 - 2 Box Drains installation of 2x2x3 with grate & pipe connectorsITEM 3 - 120 feet installation of 6” sched 40 pipeITEM 4 - 300 ton installation of PA-2A Subbase (2A stone)ITEM 5 - 1200 feet installation of Fabric, non-woven (4 rolls 1200 ft)ITEM 6 - 40 feet installation of 15“ culvert pipeITEM 7 - 140 feet installtion of 12” culvert smoothie wall pipeITEM 8 - 155 ton installtion of stone AASHTO No 1 (formerly 4)ITEM 9 - 20 ton installation of stone size R5¶ *Special Provision - Must pay prevailing wages and installation must follow PA DGLVR program guidelines.¶ NOTE: MANDATORY PRE-BID MEETING onsite April 23rd at 9:00 A.M.¶ Liquidated Damages Apply.¶ Proposals must be upon the forms furnished by the Municipality.¶ The bid must be accompanied by a certified check or bid bond in the amount of 10% of the bid, made payable to the municipality.¶ The Municipality reserves the right to reject any or all proposals.BRADY’S BENDTOWNSHIP,BY: Tammy Rondinelli,SecretaryApril 6, 2026

LEGAL MEETING NOTICE¶ Notice is hereby given by the West Liberty Borough Council that it will hold a special meeting at 7:30 P.M. on Monday, April 27, 2026, at the Borough building, 134 Rhoer Road, Slippery Rock, for the purpose of discussing and voting on appointed officials and staff.Kaylin HudsonBorough Secretary

PUBLIC NOTICEBUTLER COUNTYGENERAL AUTHORITY¶ The Butler County General Authority (“Auth-ority”) will hold a special meeting to discuss a Resolution of the Authority authorizing the Butler Area School District, on the Authority’s behalf, to refund the School Revenue Bonds, Series of 2007 (Butler Area School District Project). and for general purposes on Thursday, April 23, 2026, at 1:00 P.M., in the offices of the Community Development Corporation of Butler County, 110 East Diamond Street, Suite 201, Butler, PA 16001.

LEGAL NOTICESAXONBURGBOROUGHJOHN ROEBLING’SHISTORIC WIRE ROPE WORKSHOPRESTORATIONGeneral Notice¶ Saxonburg Borough (Owners) are requesting Bids for the construction of the following Project:John Roebling’sHistoric Wire RopeWorkshop RestorationContract No. 2026-1Bids for the construction of the Project will be received electronically via the PennBid program by Saxonburg Borough until 10:00 A.M. local time, May 26th, 2026.¶ The Project includes the following Work:¶ Structural stabilization of the existing stone and timber framing, restoration or replacement of deteriorated roofing and siding materials in-kind, masonry repair and repointing, foundation improvements, drainage enhance-ments, and installation of updated electrical and safety systems. Architectural and engineering services will guide the project to ensure compliance with local codes and the Secretary of the Interior’s Standards for the Treatment of Historic Properties. Where original materials cannot be salvaged, historically approved replacements will be used to maintain authenticity. The project is located in the Borough of Saxonburg, Butler County. The extent of the work is described in the contract documents.Obtaining the Bidding Documents¶ All project documents and details are available at no cost at (https://www.pennbid.net/)Instructions toBidders.¶ For all further requ-irements regarding bid submittal, bid security, qualifications, procedures, and contract award, refer to the Instructions to Bidders that are included in the Bidding Documents.¶ Attention is called to the fact that prevailing minimum wage rates as determined by the Secretary of the Department of Labor and Industry must be paid by the Contractors on this project and that employees and applicants for employment shall not be discriminated against because of their race, age, color, religion, sex, national origin, or handicap. Each Bidder is required to meet the requirements of Public Works Employment Verification Act, Act 127 of 2012.¶ Saxonburg Borough hereby reserves the right, which is understood and agreed to by all bidders, to refuse and reject any or all bids submitted, and also reserve the right to waive any informality in bids received.¶ Bidders must comply with all State anti-kickback regulations pertaining to work associated with this project and will be required to submit an executed anti-collusion statement with the bid.¶ Onsite pre bid inspections will be held on May 11th from 9:00 A.M. to 3:00 P.M.¶ Except as otherwise provided by law, no bidder may withdraw its bid for sixty (60) days after the Bid Due Date, unless the contract award is delayed by a required approval of another government agency, the sale of bonds, or the award of a grant or grants, in which case the Bids shall remain open to acceptance and shall be irrevocable for a period of one hundred twenty (120) days after the Bid Due Date.Steven MayBorough ManagerApril 21, 2026

LEGAL NOTICEOF FILINGFICTITIOUS NAME¶ NOTICE IS HEREBY GIVEN that Ashgrove Soaps and Sundries, LLC owners Laureen Chandler - 230 Monks Road, Valencia, PA and Stuart Chandler - 230 Monks Road, Valencia, PA have filed on April 7, 2026, in the Department of State of the Commonwealth of Pennsylvania, Harrisburg, an application under the Fictitious Names Act, approved the 24th day of May, 1945, P.L. 967, as amended, Section 311 of Act 1982-294 (54 Pa. C.S. Section 311), to conduct business under the name of Ashgrove Artisan, the business to be carried on at 230 Monks Road, Valencia, PA 16059.

LETTERSADMINISTRATIONC.T.A.¶ Letters Administration C.T.A. on the Estate of ANITA J. BONNER Court Term No. 10-26-0324 Late of Butler, Butler County, Pennsylvania, deceased, having been granted to the undersigned by the Register of Wills of Butler County, notice is hereby given to all persons indebted to said estate to make immediate payment, and to those having claims against the same to present them to the undersigned, duly authenticated for settlement.JODY LYNN NODGE,Administrator C.T.A.260 Pinehurst RoadButler, PA 16001Or to:Andrew M. Menchyk, Jr.,EsquireSTEPANIAN &MENCHYK, LLP222 South MainStreetButler, PA 16001

LEGAL NOTICEOF ZONING BOARDHEARING¶ The Harmony Borough Zoning Hearing Board will hear the following case on May 14, 2026, beginning at 6:00 P.M. at the Harmony Borough Municipal Building, 217 Mercer Street, Harmony, PA 16037, where all interested parties may attend and present evidence:¶ Case No. 2026-01 - Variance request for Anthony R. Nicoletti to reduce the rear and side yard setback to three (3) feet at 1116 Seneca Drive, Harmony, PA 16037, Tax Map Parcel 420-S2-1B36.Sean M. Gallagher,EsquireHarmony BoroughZoning Hearing BoardSolicitorGALLAGHERLAW GROUPDiamond Park Place,Suite 101110 East Diamond StreetButler, PA 16001

ADMINISTRATOR’SNOTICE¶ Estate of AMANDA NICOLE MCMANIGLE, Late of Harmony, Butler County, Pennsylvania, deceased.¶ Letters of Administration upon the above-named estate having been granted to the undersigned, all persons having claims against the estate will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to:EMILY ELISABETHHEIM,Administratorc/o Ashley E. Sharek,EsquireENTRUSTEDLEGACY LAWP.O. Box 130Bradford Woods, PA15015Ashley E. Sharek,EsquireENTRUSTEDLEGACY LAWP.O. Box 130Bradford Woods, PA15015

TRUSTADMINISTRATION¶ NOTICE is hereby given of the administration of the JOSEPH A. AND CHARITY A. MARIOTTI FAMILY IRREVOCABLE TRUST, DATED MAY 23, 2011. All persons having claims against the Trust are requested to make known the same to the trustee or attorney named below. All persons indebted to the Trust are requested to make payment without delay to the trustee or attorney named below:JOSEPH J. MARIOTTI,Trustee109 David DriveButler, PA 16001OR c/o:LYNN M. PATTERSON,Esquire1202 Oakridge DriveButler, PA 16001

LEGAL NOTICEADVERTISEMENTFOR BIDS¶ The Board of Education of the Pine-Richland School District will receive sealed proposals for Contract S06-26-01A: PAVING IMPROVE-MENTS, under single Prime Contract.¶ Bids will be accepted no later than 2:00 P.M. TUESDAY, MAY 12, 2026, at the Pine-Richland District Administration Offices, 702 Warrendale Road, Gibsonia, PA 15044-6040, c/o Barbara Williams, School Board Secretary. Bids shall be delivered in sealed envelopes clearly marked with company name and address and indicating “Paving Improvements”. Shortly thereafter, bids will be opened and read aloud, and all are invited to attend.¶ Bidders may obtain one set of Bidding Documents as follows:¶ MAIL or present to Printscape Imaging and Graphics, 760 Vista Park Drive #7, Pittsburgh, PA 15205, a refundable deposit check in the amount of $100.00, payable to PINE-RICHLAND SCHOOL DISTRICT. Write “S06-26-01A Deposit” in the Memo line and include a request on company letterhead that includes your firm name, contact person’s name, email address, UPS shipping address (no PO Box numbers), phone and fax numbers.¶ Additional sets, or partial sets, or electronic PDF files of Bidding Documents can be purchased directly from Printscape, 412-788-0640.¶ Deposit will be returned provided Bidding Documents are returned to Printscape within ten calendar days of bidding date, in good usable condition, and a Bona Fide Bid is received by the School District; otherwise deposit will be forfeited. Shipping charges are not refundable.¶ Each bid must be accompanied by a proposal guaranty of not less than ten percent (10%) of the total of the Base Bid; and by a Non-Collusion Affidavit, Qualification Questionnaire, and a Pennsylvania Certificate of Authority (if applicable).¶ Project is subject to applicable provisions of the Pennsylvania Prevai-ling Wage Act, Act of August 15, 1961, P.L. 987, as amended and supplemented.¶ Owner reserves the right to accept or reject any or all Bids or parts thereof or items therein and to waive any informality in the bidding.¶ Prime Bidders will be required to REGISTER to receive notification of Addenda and project information updates, and to obtain access privileges to the DFS Project Website at connect.MyPrintscape.com.Scheduled Site Visits:Bidders are encouraged to examine the location and existing conditions of the proposed project sites at a PRE-BID MEETING, on Friday, May 1, 2026, at 1:00 P.M. Report to Eden Hall Elementary School, 3900 Bakerstown Road, Gibsonia, PA for a short presentation and then bidders will have an opportunity to review the existing conditions at this site after the presentation. Thereafter, bidders will be able to visit the Richland Elementary School site and Wexford Elementary School site as this is an in-service day for the School District.¶ Questions pertaining to the content of the Bidding Documents shall be directed to Mark Scheller and Megan Vercilla, DRAW Collective) by email at MarkS@DRAW collective.com and meganv@drawcollective.com respectively and copy to Terri Hoover, Eckles Construction Services, by email at tkh@ecklesgroup.com. Questions must be submitted using the Pre-Bid RFI form available on the DFS Project Website. Phone calls will not be accepted.

LEGAL NOTICE¶ The supervisors of Allegheny Township, Butler County, will hold a special meeting at 7:00 P.M., Monday, April 27, regarding a resolution for plan revision for new land development for a single residence sewage treatment plant. The meeting will be held at the municipal building, 375 Foxburg Road, Parker, PA 13049.

LEGAL NOTICEOF INTENT TOADOPT ORDINANCE¶ The Summit Township Board of Supervisors will, at its regularly schedule meeting on May 6, 2026, at 6:45 P.M., at the Summit Township Municipal Buil-ding, 502 Bonniebrook Road, Butler, PA 16002, vote on adopting an Ordinance which is entitled “An Ordinance Regu-lating the Business of Transient Merchants Within the Township of Summit, Butler County, Pennsylvania, Requiring Transient Merchants to Obtain Licenses, Establishing License Fees, Providing for the Enfor-cement of the Provisions of the Ordinance and Penalties for Violations Thereof.”¶ A summary of the Ordinance is as follows:¶ Section 101 - Sets forth definitions of “soliciting,” “peddling,” and “canvassing”. Sets forth exceptions for farmers selling their goods, the sale of goods by IRS tax-exempt entities, the sale of goods for school projects or activities, and persons providing proof of compliance with the Pa. Solicitation of Funds for Charitable Purposes Act.¶ Section 102 - States the prohibition of solicitation or peddling without a license.¶ Section 103 - Sets forth the application requirements.¶ Section 104 - Fees are to be established by Resolution of the Supervisors.¶ Section 105 - Licenses are for a maximum period of one month and then must be renewed.¶ Section 106 - Sets forth standard of conduct, prohibits operations on Sundays or official holidays, and limits operations from 9:30 A.M. to 8:00 P.M.¶ Section 107 - The Code Enforcement Officer of Summit Township will maintain all records.¶ Section 108 - Sets forth the bases for the suspension of licenses.¶ Section 109 - Sets forth the process of appeal from suspended licenses.¶ Section 110 - Sets forth prohibition upon the utilization of “hawking or crying,” loudspeakers, bells, whistles, and the like, and electronic or flashing signage.¶ Section 111 - Establishes a fine of $600.00, plus court costs and attorney’s fees for the violation of the Ordinance.¶ Section 112 - Sets forth a severability clause.¶ Section 113 - Sets forth a repealer clause.¶ Copies of the full text of the Ordinance are available at the Summit Township Municipal Bui-lding during regular office hours, the Butler County Law Library (located in the Butler County Court-house), Butler, Pennsylvania, and at this newspaper and may be examined without charge or obtained for a charge not greater than the cost thereof.Michael D. Gallagher,EsquireSummit TownshipSolicitorGALLAGHERLAW GROUP110 East DiamondStreet, Suite 101Butler, PA 16001

LEGAL NOTICEOF PUBLIC SALE OFSTORED PROPERTY¶ Notice is hereby given that the undersigned will sell, to satisfy the lien of the landlord, at A public sale by competitive bidding on May 5, 2026, at 10:00 A.M. by Rent A Space Self Storage located at 1292 Dutilh Road, Cranberry Township, PA 16066, all stored items in the following space numbers by the following Tenants:Daniel Gitani, Space #4H71; Jermaine Revis, Space #256. All goods are sold as-is and must be removed at the time of purchase, Rent A Space Reserves the right to bid. Sale is subject to adjournment.

LEGAL NOTICEIN THE COURT OFCOMMON PLEAS OFBUTLER COUNTY,PENNSYLVANIACIVIL ACTION - EQUITYNO. 26-10344ACTION TOQUIET TITLESUBURBAN PA PROPERTY ACQUISITIONS, LLC,Plaintiff,¶ vs.AGWAY ENERGY PRODUCTS LLC, SUCCESSOR BY MERGER TO AGWAY PETROLEUM CORP.,DefendantNOTICE¶ YOU HAVE BEEN SUED IN COURT. IF YOU WISH TO DEFEND AGAINST THE CLAIMS SET FORTH IN THE FOLLOWING PAGES, YOU MUST TAKE ACTION WITHIN TWENTY (20) DAYS AFTER THIS COMPLAINT AND NOTICE ARE SERVED, BY ENTERING A WRITTEN APPEARANCE PERSONALLY OR BY ATTORNEY AND FILING IN WRITING WITH THE COURT YOUR DEFE-NSES OR OBJECTIONS TO THE CLAIMS SET FORTH AGAINST YOU. YOU ARE WARNED THAT IF YOU FAIL TO DO SO THE CASE MAY PROCEED WITHOUT YOU AND A JUDGMENT MAY BE ENTERED AGAINST YOU BY THE COURT WITHOUT FURTHER NOTICE FOR ANY MONEY CLAIMED IN THE COMPLAINT OR FOR ANY OTHER CLAIM OR RELIEF REQUESTED BY THE PLAINTIFF. YOU MAY LOSE MONEY OR PROPERTY OR OTHER RIGHTS IMPORTANT TO YOU.¶ YOU SHOULD TAKE THIS PAPER TO YOUR LAWYER AT ONCE. IF YOU DO NOT HAVE A LAWYER, GO TO OR TELEPHONE THE OFFICE SET FORTH BELOW. THIS OFFICE CAN PROVIDE YOU WITH INFORMATION ABOUT HIRING A LAWYER.¶ IF YOU CANNOT AFFORD TO HIRE A LAWYER, THIS OFFICE MAY BE ABLE TO PROVIDE YOU WITH INFORMATION ABOUT AGENCIES THAT MAY OFFER LEGAL SERVICES TO ELIGIBLE PERSONS AT A REDUCED FEE OR NO FEE.Butler CountyBar Association240 South Main StreetButler, PA 16001Phone: 724.841.0130Office of the Prothonotary,Butler CountyButler CountyGovernment Center124 West Diamond StreetButler, PA 16001Phone: 724.284.6214NORRIS McLAUGHLIN, P.A.David C. Berger,EsquireAttorney ID No. 311285

LEGAL MEETING NOTICE¶ Notice is hereby given by the West Liberty Borough Council that it will hold a special meeting at 7:30 P.M. on Monday, April 27, 2026, at the Borough building, 134 Rhoer Road, Slippery Rock, for the purpose of discussing and voting on appointed officials and staff.Kaylin HudsonBorough Secretary

LEGAL NOTICEOF ZONING BOARDHEARING¶ The Harmony Borough Zoning Hearing Board will hear the following case on May 14, 2026, beginning at 6:00 P.M. at the Harmony Borough Municipal Building, 217 Mercer Street, Harmony, PA 16037, where all interested parties may attend and present evidence:¶ Case No. 2026-01 - Variance request for Anthony R. Nicoletti to reduce the rear and side yard setback to three (3) feet at 1116 Seneca Drive, Harmony, PA 16037, Tax Map Parcel 420-S2-1B36.Sean M. Gallagher,EsquireHarmony BoroughZoning Hearing BoardSolicitorGALLAGHERLAW GROUPDiamond Park Place,Suite 101110 East Diamond StreetButler, PA 16001

LEGAL NOTICEOF PUBLIC SALE¶ Lock Solid Storage - Clearview selling property to satisfy a landlord’s lien for nonpayment of rent. Sale to be held online at Bid13.com. Facility located at 101 Clearview Circle Butler, PA 16001. Auction Bidding will close on or after May 25th 2026 at 10:00 A.M. Cleanup deposit is required. Seller reserves the right to withdraw the property at any time before the sale. Unit items sold as-is to the highest bidder. Property includes the contents of spaces of the following tenant(s): All spaces contain household items unless noted.Alycia Adams - Unit 8(4-24, 5-1-26)

LEGAL NOTICE¶ Fairview Township, Butler County will hold a special meeting on Monday April 27th at 6:00 PM at the Municipal Building, for the purpose of opening Seal Coat Bids.

LETTERSADMINISTRATIONC.T.A.¶ Letters Administration C.T.A. on the Estate of ANITA J. BONNER Court Term No. 10-26-0324 Late of Butler, Butler County, Pennsylvania, deceased, having been granted to the undersigned by the Register of Wills of Butler County, notice is hereby given to all persons indebted to said estate to make immediate payment, and to those having claims against the same to present them to the undersigned, duly authenticated for settlement.JODY LYNN NODGE,Administrator C.T.A.260 Pinehurst RoadButler, PA 16001Or to:Andrew M. Menchyk, Jr.,EsquireSTEPANIAN &MENCHYK, LLP222 South MainStreetButler, PA 16001

LEGAL NOTICE¶ The annual meeting of the Pleasant Valley Cemetery Association will be held on May 5, 2026 at 7:00 P.M. at the Pleasant Valley Cemetery, 147 Pleasant Valley Road, West Sunbury, PA 16061. If you need more information, please call Don or Judy at 724-256-6242.

LEGAL NOTICE¶ The supervisors of Allegheny Township, Butler County, will hold a special meeting at 7:00 P.M., Monday, April 27, regarding a resolution for plan revision for new land development for a single residence sewage treatment plant. The meeting will be held at the municipal building, 375 Foxburg Road, Parker, PA 13049.

LEGAL NOTICEOF INTENT TOADOPT ORDINANCE¶ The Summit Township Board of Supervisors will, at its regularly schedule meeting on May 6, 2026, at 6:45 P.M., at the Summit Township Municipal Buil-ding, 502 Bonniebrook Road, Butler, PA 16002, vote on adopting an Ordinance which is entitled “An Ordinance Regu-lating the Business of Transient Merchants Within the Township of Summit, Butler County, Pennsylvania, Requiring Transient Merchants to Obtain Licenses, Establishing License Fees, Providing for the Enfor-cement of the Provisions of the Ordinance and Penalties for Violations Thereof.”¶ A summary of the Ordinance is as follows:¶ Section 101 - Sets forth definitions of “soliciting,” “peddling,” and “canvassing”. Sets forth exceptions for farmers selling their goods, the sale of goods by IRS tax-exempt entities, the sale of goods for school projects or activities, and persons providing proof of compliance with the Pa. Solicitation of Funds for Charitable Purposes Act.¶ Section 102 - States the prohibition of solicitation or peddling without a license.¶ Section 103 - Sets forth the application requirements.¶ Section 104 - Fees are to be established by Resolution of the Supervisors.¶ Section 105 - Licenses are for a maximum period of one month and then must be renewed.¶ Section 106 - Sets forth standard of conduct, prohibits operations on Sundays or official holidays, and limits operations from 9:30 A.M. to 8:00 P.M.¶ Section 107 - The Code Enforcement Officer of Summit Township will maintain all records.¶ Section 108 - Sets forth the bases for the suspension of licenses.¶ Section 109 - Sets forth the process of appeal from suspended licenses.¶ Section 110 - Sets forth prohibition upon the utilization of “hawking or crying,” loudspeakers, bells, whistles, and the like, and electronic or flashing signage.¶ Section 111 - Establishes a fine of $600.00, plus court costs and attorney’s fees for the violation of the Ordinance.¶ Section 112 - Sets forth a severability clause.¶ Section 113 - Sets forth a repealer clause.¶ Copies of the full text of the Ordinance are available at the Summit Township Municipal Bui-lding during regular office hours, the Butler County Law Library (located in the Butler County Court-house), Butler, Pennsylvania, and at this newspaper and may be examined without charge or obtained for a charge not greater than the cost thereof.Michael D. Gallagher,EsquireSummit TownshipSolicitorGALLAGHERLAW GROUP110 East DiamondStreet, Suite 101Butler, PA 16001

TRUSTADMINISTRATION¶ NOTICE is hereby given of the administration of THE MARY R. SHRAMOWICK REVOCABLE TRUST. All persons having claims against the Trust are requested to make known the same to the trustee or attorney named below. All persons indebted to the Trust are requested to make payment without delay to the trustee or attorney named below:JOHN G. SHRAM,Trustee12921 Cantrell RoadSuite 309Little Rock, AR 72223Or:c/o Lynn M. Patterson,Esquire1202 Oakridge DriveButler, PA 16001

ESTATE NOTICE¶ Estate of PATRICIA G. OSCHE, Deceased, late of Butler, Butler County, PA File No. 10-26-0310. Letters Testamentary on his estate were granted to the undersigned who requests all persons having claims or demands against the estate of the decedent to make known the same, and all persons indebted to decedent to make payment without delay to:ADA RUMBURG,Executrix403 Mahood RoadButler, PA 16001Paula J. Willyard,EsquireWILLYARD LAWFIRM PC382 North Pike RoadSarver, PA 16055

ESTATE NOTICE¶ Estate of SANDRA L. MEANOR, Deceased, late of Cranberry Township, Butler County, PA File No. 10-26-0374. Letters Testamentary on her estate were granted to the undersigned who requests all persons having claims or demands against the estate of the decedent to make known the same, and all persons indebted to decedent to make payment without delay to:CHARLA V. PFEIFFER,Executrix310 South DriveValencia, PA 16059Paula J. Willyard,EsquireWILLYARD LAWFIRM PC382 North Pike RoadSarver, PA 16055

LEGAL NOTICEADVERTISEMENTFOR BIDSNORTH ALLEGHENYSCHOOL DISTRICTFor Refuse andRecycling ServicesAt Various Locations and Properties¶ North Allegheny Sch-ool District, the Owner, will receive separate sealed Bids for the Contract on the services until the time, date, and place scheduled below. The Bids will be publicly opened and read aloud in the Conference Room of the Facilities/Trans-portation Offices. The clock in the Conference Room will determine prevailing time for receipt of bids. The District invites interested parties to attend.BID DUE DATE:Monday April 27, 2026BID DUE/OPENINGTIME: 1:00 P.M.,Prevailing TimePLACE OF RECEIPT:North AlleghenySchool DistrictTransportation/AssetsDepartmentc/o Ms. Jaimie NicholsPurchasing ManagerPLACE OF OPENING:Facilities/TransportationOfficeConference Room400 Hillvue LanePittsburgh, PA 15237¶ Bidders may obtain one complete set of the Bidding Documents for these services by emailing:JaSchwoebel@northallegheny.org¶ The Owner reserves the right to reject any or all Bids and to waive any informalities or irregu-larities in any Bid received.¶ For more information on this project, please email:Mr. Jason Schwoebel atjaschwoebel@northallegheny.org

TRUSTADMINISTRATION¶ NOTICE is hereby given of the administration of the JOSEPH A. AND CHARITY A. MARIOTTI FAMILY IRREVOCABLE TRUST, DATED MAY 23, 2011. All persons having claims against the Trust are requested to make known the same to the trustee or attorney named below. All persons indebted to the Trust are requested to make payment without delay to the trustee or attorney named below:JOSEPH J. MARIOTTI,Trustee109 David DriveButler, PA 16001OR c/o:LYNN M. PATTERSON,Esquire1202 Oakridge DriveButler, PA 16001

LEGAL NOTICE¶ Sealed proposals will be received by the BRADY’S BEND TOWNSHIP of Armstrong County at 1004 State Route 68, East Brady, PA 16028 until 1:00 P.M., on May 4, 2026, for the following: ITEM 1 - 1200 feet installation of 6“ perf coiled pipeITEM 2 - 2 Box Drains installation of 2x2x3 with grate & pipe connectorsITEM 3 - 120 feet installation of 6” sched 40 pipeITEM 4 - 300 ton installation of PA-2A Subbase (2A stone)ITEM 5 - 1200 feet installation of Fabric, non-woven (4 rolls 1200 ft)ITEM 6 - 40 feet installation of 15“ culvert pipeITEM 7 - 140 feet installtion of 12” culvert smoothie wall pipeITEM 8 - 155 ton installtion of stone AASHTO No 1 (formerly 4)ITEM 9 - 20 ton installation of stone size R5¶ *Special Provision - Must pay prevailing wages and installation must follow PA DGLVR program guidelines.¶ NOTE: MANDATORY PRE-BID MEETING onsite April 23rd at 9:00 A.M.¶ Liquidated Damages Apply.¶ Proposals must be upon the forms furnished by the Municipality.¶ The bid must be accompanied by a certified check or bid bond in the amount of 10% of the bid, made payable to the municipality.¶ The Municipality reserves the right to reject any or all proposals.BRADY’S BENDTOWNSHIP,BY: Tammy Rondinelli,SecretaryApril 6, 2026

LEGAL NOTICEOF FILINGFICTITIOUS NAME¶ NOTICE IS HEREBY GIVEN that Ashgrove Soaps and Sundries, LLC owners Laureen Chandler - 230 Monks Road, Valencia, PA and Stuart Chandler - 230 Monks Road, Valencia, PA have filed on April 7, 2026, in the Department of State of the Commonwealth of Pennsylvania, Harrisburg, an application under the Fictitious Names Act, approved the 24th day of May, 1945, P.L. 967, as amended, Section 311 of Act 1982-294 (54 Pa. C.S. Section 311), to conduct business under the name of Ashgrove Artisan, the business to be carried on at 230 Monks Road, Valencia, PA 16059.