Are You Sure?

LEGAL NOTICEADVERTISEMENTFOR BIDS¶ The Allegheny-Clarion Valley School District, a public school entity in Clarion County, Pennsylvania, is soliciting sealed proposals from qualified vendors for the replacement of football field lighting fixtures on six (6) existing poles at the District’s athletic stadium.¶ A mandatory site visit will be held at 10:00 A.M. on May 6, 2026.¶ These bids will be accepted until May 6, 2026 at noon. Address them to Dr. David McDeavitt at the A-C Valley School District, 776 PA 58, Foxburg, PA 16036. Bids will be opened at that time.¶ Please contact the District Office for additional information at 724-659-5820.¶ The owner reserves the right to accept or reject any and all bids and to waive any informalities in the bid.

EXECUTOR’S NOTICE¶ Estate of MARLENE Y. WRIGHT, Late of Cranberry Township, Butler County, Pennsylvania, deceased.¶ Letters testamentary upon the above-named estate having been granted to the undersigned, at Estate File No. 10-26-0390, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to:MARK R. WRIGHT,Executor1411 Grandview Ave.Apt. 811Pittsburgh, PA 15211

EXECUTRIX’S NOTICE¶ Estate of RALPH A. KACY JR., Late of Sarver, Butler County, Pennsylvania, deceased.¶ Letters Testamentary upon the above-named estate having been granted to the undersigned, at Estate File No. 10-26-0386, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to:SHERRY L.PIVIROTTO,Executrixc/oMallory P. Gold,EsquireGOLD LAW, LLCOne Monroeville CenterSuite 1075Monroeville, PA 15146

LEGAL NOTICE TOWNSHIP OF JACKSON - NOTICE OF ENACTMENT UNDER LOCAL GOVERNMENT UNIT DEBT ACT Notice is hereby given that the Board of Supervisors of the Township of Jackson (Butler County, PA) at a special meeting held on Thursday, April 30, 2026, enacted an ordinance authorizing the issuance of lease rental debt by the guaranty of a Revenue Obligation Note of the Jackson Municipal Authority and the private sale thereof to WesBanco, Inc. in the principal amount of $3,000,000.00 dollars bearing interest at the rate of 4.91% per annum for the first 5 years of the Note that will then convert to the Five Year Treasury rate plus 0.09% at the 60th month and 120th month thereafter until paid with the range of the lease rental payments due by the Township being $0 to $3,000,000.00 plus interest. The range of annual payments is from $0 to $240,282.88 with a balloon payment at 132 months of $0 to $2,097,649.94. The Townships officers are directed to do all acts necessary and proper for the issuance and securing of said Note. No amendments were made during the final passage of this ordinance. The full text of the Ordinance as enacted may be examined by any citizen between the hours of 7:00 A.M. and 5:00 P.M., Monday through Friday at the Jackson Township Municipal Building, located at 140 Magill Road, Zelienople, PA 16063. Chris Rearick Township Manager (724) 452-5581 crearick@jackson- township.com Date Advertised: May 4, 2026

LEGAL NOTICE¶ Notice is hereby given the Butler County Area Vocational-Technical School Authority Board will meet in the Conference Room, 210 Campus Lane, Butler, PA 16001 at 6:30 P.M., Thursday, May 7, 2026.Jeffery Schnur,SecretaryButler County AVTSAuthority Board

LEGAL NOTICE ADVERTISEMENT FOR BIDS JACKSON TOWNSHIP, BUTLER COUNTY, PENNSYLVANIA COMMUNITY AND CONCESSION BUILDING General Notice Jackson Township (Owner) is requesting Bids for the construction of the following project: Community and Concessions Building Contract No 25-62 Bids for the construction of the Project will be received by Jackson Township, online via PennBid, until Monday, June 1, 2026 at 2:00 P.M. local time. The Project includes the Construction of a new concession area with covered seating, ADA men & women toilet rooms, a community room, offices, and a mechanical/janitor room. Separate Bids will be received for the following Contracts: Contract No. 25.62A GENERAL CONSTRUCTION Contract No. 25.62B HVAC CONSTRUCTION Contract No. 25.62C PLUMBING CONSTRUCTION Contract No. 25.62D ELECTRICAL CONSTRUCTION Information and Bidding Documents for the Project can be found at the following designated website: https://pennbid. bonfirehub.com Bidding Documents may be downloaded from the designated website. Prospective Bidders are urged to register with the designated website as a plan holder, even if Bidding Documents are obtained from a plan room or source other than the designated website in either electronic or paper format. The designated website will be updated periodically with addenda, lists of registered plan holders, reports, and other information relevant to submitting a Bid for the Project. All official notifications, addenda, and other Bidding Documents will be offered only through the designated website. Neither Owner nor Engineer will be responsible for Bidding Documents, including addenda, if any, obtained from sources other than the designated website. All bidders must submit bid security of a Certified Check or Bid Bond in the amount of 10% of the Base Bid. All bids shall be irrevocable for 90 days after the bid opening date as provided by the Act of November 26, 1978 (P.L. 1309, No. 317), as amended by the Act of December 12, 1994 (P.L. 1042, No. 142). Owner: Jackson Township By: Chris Rearick Title: Township Manager Date: April 2026

LEGAL NOTICE Estate of RICHARD C. DUNLAP a/k/a RICHARD CLINTON DUNLAP: Letters Testamentary on the above Estate have been granted to the undersigned, who requests all persons having claims or demands against the Estate of the decedent to make known the same, and all persons indebted to the decedent to make payment without delay to: NANCY L. BARNETT, Executor 3855 South Courtenay Parkway Merritt Island, FL 32952 Or to: Raymond H. Bogaty, Esquire BOGATY LAW OFFICE, P.C. 101 South Center Street P.O. Box 825 Grove City, Pennsylvania 16127

LEGAL NOTICE¶ Sealed proposals will bereceived by the Adams Township of Butler County at 690 Valencia Road, Mars, PA 16046 until 12:00 P.M., on May 11, 2026, for the following: ITEM 1 - 44,420 S.Y. - SINGLE ASPHALTFIBER REINF SEAL COAT, IN PLACE, Slag AggITEM 2 - 44,420 S.Y. - ASPHALT FOG SEAL FOR ASPHALT SEAL COATSITEM 3 - 3,207 S.Y. - DOUBLE ASPHALT SEAL COAT, IN PLACE¶ Liquidated damages apply at the rate of $975.00 per calendar day.¶ Proposals must be upon the forms furnished by the Municipality.¶ For third class cities the bid must be accompanied by a certified check or bid bond in the amount of 10% of the bid, made payable to the municipality. For other municipal types it is the discretion of the municipality.¶ A performance bond or certified check in the amount of 100% of the contract shall be furnished by the successful bidder within 20 days after the contract is awarded.¶ The Municipality reserves the right to reject any or all proposals.Adams TownshipBY: Mike TylkaSecretary/Treasurer

LEGAL NOTICEOF PUBLIC SALE¶ Lock Solid Storage - Clearview selling property to satisfy a landlord’s lien for nonpayment of rent. Sale to be held online at Bid13.com. Facility located at 101 Clearview Circle Butler, PA 16001. Auction Bidding will close on or after May 25th 2026 at 10:00 A.M. Cleanup deposit is required. Seller reserves the right to withdraw the property at any time before the sale. Unit items sold as-is to the highest bidder. Property includes the contents of spaces of the following tenant(s): All spaces contain household items unless noted.Alycia Adams - Unit 8(4-24, 5-1-26)

LEGAL NOTICE OF ZONING BOARD HEARING The Harmony Borough Zoning Hearing Board will hear the following case on May 14, 2026, beginning at 6:00 P.M. at the Harmony Borough Municipal Building, 217 Mercer Street, Harmony, PA 16037, where all interested parties may attend and present evidence: Case No. 2026-02 - Variance request for Dean R. Marks to reduce the minimum lot width from 60 feet to 48 feet at 247 Mercer Street, Harmony, PA 16037, Tax Map Parcel 420-S1-B26. Case No. 2026-03 - Variance request for Luke R. Meeder to reduce the side yard setback for an accessory structure from 10 feet to 5 feet at 756 Spring Street, Harmony, PA 16037, Tax Map Parcel 420-S1-M4. Sean M. Gallagher, Esquire Harmony Borough Zoning Hearing Board Solicitor GALLAGHER LAW GROUP Diamond Park Place, Suite 101 110 East Diamond Street Butler, PA 16001

LEGAL NOTICE RESIDENTS AND TAXPAYERS PENN TOWNSHIP BUTLER COUNTY The Penn Township Park Committee will meet on May 11, 2026, at 6:00 P.M. at Harcrest Park, 830 Three Degree Road, Butler, PA 16002 Linda D. Zerfoss Township Manager May 6, 2026

LEGAL NOTICE¶ Sealed proposals will be received by the Buffalo Township of Butler County at 109 Bear Creek Road, Sarver, PA 16055 until 12:00 P.M., on May 13, 2026, for the following: ¶ ITEM 1 - 10,549 S.Y. - MILLING OF ASPHALT¶ ITEM 2 - 976 TON - ASPHALT WEARING COURSE, 9.5mm, IN PLACE¶ ITEM 3 - 1,073 TON - ASPHALT BINDER COURSE, 19.0mm, IN PLACE¶ Note: Prevailing wage rates shall apply to this contract.¶ Liquidated damages apply at the rate of $975.00 per calendar day.¶ Proposals must be upon the forms furnished by the Municipality.¶ For third class cities the bid must be accompanied by a certified check or bid bond in the amount of 10% of the bid, made payable to the municipality. For other municipal types it is the discretion of the municipality.¶ A performance bond or certified check in the amount of 100% of the contract shall be furnished by the successful bidder within 20 days after the contract is awarded.¶ The Municipality reserves the right to reject any or all proposals.Buffalo TownshipBY: Janice HumesZubrinSecretary/Treasurer

EXECUTOR’S NOTICE¶ Estate of LEONA M DeROSIA, Late of Renfrew, Butler County, Pennsylvania, deceased.¶ Letters testamentary upon the above-named estate having been granted to the undersigned, at Estate File No. 10-26-0392, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to:ELIZABETH A. HENRY,Executor709 Landis RoadFreedom, PA 15042

EXECUTORS NOTICE Estate of ESTA D. WEISS, Late of Cranberry Township, Butler County, Pennsylvania, deceased. Letters Testamentary upon the above-named estate having been granted to the undersigned at Estate File No. 10-25-1290, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to: BETH D. BOSLEY, Executor c/o Dentons Cohen & Grigsby, P.C. 625 Liberty Avenue Pittsburgh, PA 15222-3152 or to: Lauren C. Hadburg, Esquire DENTONS COHEN & GRIGSBY, P.C. 625 Liberty Avenue Pittsburgh, PA 15222-3152

CO-EXECUTORS NOTICE Estate of BETTY G. KREUTZ a/k/a BETTY GRACE KREUTZ, late of West Liberty, Butler County, Pennsylvania, Deceased. Letters Testamentary upon the above-named estate having been granted to the undersigned, at File No. 10-26-0434, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to: TODD A. KREUTZ, Co-Executor 150 Church Road Slippery Rock, PA 16057 or: SCOTT A. KREUTZ, Co-Executor 307 Studebaker Road Slippery Rock, PA 16057 or: JAMIE A. KREUTZ, Co-Executor 119 West Park Road Portersville, PA 16051 Ronald W. Coyer, Esquire S.R. LAW, LLC 631 Kelly Boulevard P.O. Box 67 Slippery Rock, PA 16057

EXECUTOR’S NOTICE¶ Estate of LEONA M DeROSIA, Late of Renfrew, Butler County, Pennsylvania, deceased.¶ Letters testamentary upon the above-named estate having been granted to the undersigned, at Estate File No. 10-26-0392, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to:ELIZABETH A. HENRY,Executor709 Landis RoadFreedom, PA 15042

LEGAL NOTICE OF SELF STORAGE SALE Notice is hereby given that E&E Butler Properties at 531 Woodhawk Lane, Butler, PA 16001 being the owner of all storage units on its premises at 900 Castle-ridge Lane, Butler PA 16001 will be disposing of the contents of the following unit(s) to satisfy the lien created by the non-payment of rent. Disposal will be FRIDAY, MAY 29, 2026 for the following name(s) and unit(s): Gregg Collins, Unit A-16 and Rev. Rick Comperatore, Unit C-14.

LEGAL NOTICE OF VOLUNTARY DISSOLUTION BY BUSINESS CORPORATION Notice is hereby given by Keystone Crystal Corporation, a Pennsylvania business corporation, that said corporation is winding up its affairs in the manner prescribed by the Business Corporation Law of 1988, as amended, so that its corporate existence shall cease upon the filing of Articles of Dissolution in the Department of State of the Commonwealth of Pennsylvania. CHARLES D. SCHOLZ, ESQUIRE 401 Liberty Avenue 22nd Floor Three Gateway Center Pittsburgh, Pennsylvania 15222

LEGAL NOTICE COURT OF COMMON PLEAS OF BUTLER COUNTY U.S. Bank Trust National Association, not in its individual capacity but sol-ely as Trustee for RCAF Acquisition Trust v. David Watterson, known heir of Barbara A. Watterson and/or Roger D. Moffett, et al; Court No. 17-10680; 24-20838; 24-30135 To: Colin Borland, known heir of Karen Watterson a/k/a Karen Zavacky. You have been sued in Court. If you wish to defend against the claims set forth in the Amended Complaint in Mortgage Foreclosure, you must take action within twenty (20) days after this publication, by entering a written appearance personally or by attorney and filing in writing with the Court your defenses or objections to the claims set forth against you. You are warned that if you fail to do so, the case may proceed without you and a judgment may be entered against you by the Court without further notice. You may lose money or property or other rights important to you. You should take this publication to your lawyer at once. If you do not have a lawyer, go to or telephone the office set forth below. This office can provide you with information about hiring a lawyer. If you cannot afford to hire a lawyer, this office may be able to provide you with information about agencies that may offer legal services to eligible persons at a reduced fee or no fee. Butler County Bar Association, 240 South Main Street, Butler, PA 16001, 724-842-0130 or Office of the Prothonotary, Butler County, Butler County Government Center, 124 West Diamond Street, Butler, PA 16001, 724-284-5214. ROMANO, GARUBO & ARGENTIERI, LLC, Attorneys for Plaintiff, 52 Newton Avenue Woodbury, NJ 08096 856-384-1515

EXECUTORS NOTICE Estate of ESTA D. WEISS, Late of Cranberry Township, Butler County, Pennsylvania, deceased. Letters Testamentary upon the above-named estate having been granted to the undersigned at Estate File No. 10-25-1290, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to: BETH D. BOSLEY, Executor c/o Dentons Cohen & Grigsby, P.C. 625 Liberty Avenue Pittsburgh, PA 15222-3152 or to: Lauren C. Hadburg, Esquire DENTONS COHEN & GRIGSBY, P.C. 625 Liberty Avenue Pittsburgh, PA 15222-3152

LEGAL NOTICE RESIDENTS AND TAXPAYERS PENN TOWNSHIP BUTLER COUNTY The Penn Township Park Committee will meet on May 11, 2026, at 6:00 P.M. at Harcrest Park, 830 Three Degree Road, Butler, PA 16002 Linda D. Zerfoss Township Manager May 6, 2026

LEGAL NOTICE OF ZONING BOARD HEARING The Harmony Borough Zoning Hearing Board will hear the following case on May 14, 2026, beginning at 6:00 P.M. at the Harmony Borough Municipal Building, 217 Mercer Street, Harmony, PA 16037, where all interested parties may attend and present evidence: Case No. 2026-02 - Variance request for Dean R. Marks to reduce the minimum lot width from 60 feet to 48 feet at 247 Mercer Street, Harmony, PA 16037, Tax Map Parcel 420-S1-B26. Case No. 2026-03 - Variance request for Luke R. Meeder to reduce the side yard setback for an accessory structure from 10 feet to 5 feet at 756 Spring Street, Harmony, PA 16037, Tax Map Parcel 420-S1-M4. Sean M. Gallagher, Esquire Harmony Borough Zoning Hearing Board Solicitor GALLAGHER LAW GROUP Diamond Park Place, Suite 101 110 East Diamond Street Butler, PA 16001

LEGAL NOTICE TOWNSHIP OF JACKSON - NOTICE OF ENACTMENT UNDER LOCAL GOVERNMENT UNIT DEBT ACT Notice is hereby given that the Board of Supervisors of the Township of Jackson (Butler County, PA) at a special meeting held on Thursday, April 30, 2026, enacted an ordinance authorizing the issuance of lease rental debt by the guaranty of a Revenue Obligation Note of the Jackson Municipal Authority and the private sale thereof to WesBanco, Inc. in the principal amount of $3,000,000.00 dollars bearing interest at the rate of 4.91% per annum for the first 5 years of the Note that will then convert to the Five Year Treasury rate plus 0.09% at the 60th month and 120th month thereafter until paid with the range of the lease rental payments due by the Township being $0 to $3,000,000.00 plus interest. The range of annual payments is from $0 to $240,282.88 with a balloon payment at 132 months of $0 to $2,097,649.94. The Townships officers are directed to do all acts necessary and proper for the issuance and securing of said Note. No amendments were made during the final passage of this ordinance. The full text of the Ordinance as enacted may be examined by any citizen between the hours of 7:00 A.M. and 5:00 P.M., Monday through Friday at the Jackson Township Municipal Building, located at 140 Magill Road, Zelienople, PA 16063. Chris Rearick Township Manager (724) 452-5581 crearick@jackson- township.com Date Advertised: May 4, 2026

EXECUTOR’S NOTICE¶ Estate of DONNA MAE TURNER, a/k/a DONNA M. TURNER, a/k/a DONNA TURNER, Late of Mars, Butler County, Pennsylvania, deceased.¶ Letters testamentary upon the above-named estate having been granted to the undersigned, at Estate File No. 10-26-0308, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to:KIMBERLY LYNNBLYSTONE,Executor579 Dodds RoadButler, PA 16002John Linkosky,EsquireJOHN LINKOSKY &ASSOCIATES715 Washington AvenueCarnegie, PA 15106

EXECUTOR’S NOTICE¶ Estate of PAULA J. RIGGS a/k/a PAULA RIGGS, Late of the City of Butler, Butler County, Pennsylvania, deceased.¶ Letters testamentary upon the above-named estate having been granted to the undersigned, at Estate File No. 10-26-0395, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to:DANA MUTH,Executorc/o Gerlach LawCenter, P.C.3612 McKnight East DrivePittsburgh, PA 15237Gregory D. Gerlach,EsquireGERLACH LAW CENTER, P.C.3612 McKnight East DrivePittsburgh, PA 15237

LEGAL NOTICE¶ Sealed proposals will be received by the Buffalo Township of Butler County at 109 Bear Creek Road, Sarver, PA 16055 until 12:00 P.M., on May 13, 2026, for the following: ¶ ITEM 1 - 10,549 S.Y. - MILLING OF ASPHALT¶ ITEM 2 - 976 TON - ASPHALT WEARING COURSE, 9.5mm, IN PLACE¶ ITEM 3 - 1,073 TON - ASPHALT BINDER COURSE, 19.0mm, IN PLACE¶ Note: Prevailing wage rates shall apply to this contract.¶ Liquidated damages apply at the rate of $975.00 per calendar day.¶ Proposals must be upon the forms furnished by the Municipality.¶ For third class cities the bid must be accompanied by a certified check or bid bond in the amount of 10% of the bid, made payable to the municipality. For other municipal types it is the discretion of the municipality.¶ A performance bond or certified check in the amount of 100% of the contract shall be furnished by the successful bidder within 20 days after the contract is awarded.¶ The Municipality reserves the right to reject any or all proposals.Buffalo TownshipBY: Janice HumesZubrinSecretary/Treasurer

EXECUTRIX’S NOTICE¶ Estate of RALPH A. KACY JR., Late of Sarver, Butler County, Pennsylvania, deceased.¶ Letters Testamentary upon the above-named estate having been granted to the undersigned, at Estate File No. 10-26-0386, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to:SHERRY L.PIVIROTTO,Executrixc/oMallory P. Gold,EsquireGOLD LAW, LLCOne Monroeville CenterSuite 1075Monroeville, PA 15146

LEGAL NOTICE¶ Sealed proposals will bereceived by the Adams Township of Butler County at 690 Valencia Road, Mars, PA 16046 until 12:00 P.M., on May 11, 2026, for the following: ITEM 1 - 44,420 S.Y. - SINGLE ASPHALTFIBER REINF SEAL COAT, IN PLACE, Slag AggITEM 2 - 44,420 S.Y. - ASPHALT FOG SEAL FOR ASPHALT SEAL COATSITEM 3 - 3,207 S.Y. - DOUBLE ASPHALT SEAL COAT, IN PLACE¶ Liquidated damages apply at the rate of $975.00 per calendar day.¶ Proposals must be upon the forms furnished by the Municipality.¶ For third class cities the bid must be accompanied by a certified check or bid bond in the amount of 10% of the bid, made payable to the municipality. For other municipal types it is the discretion of the municipality.¶ A performance bond or certified check in the amount of 100% of the contract shall be furnished by the successful bidder within 20 days after the contract is awarded.¶ The Municipality reserves the right to reject any or all proposals.Adams TownshipBY: Mike TylkaSecretary/Treasurer

EXECUTOR’S NOTICE¶ Estate of NANCY J. NEAL a/k/a NANCY JEAN NEAL, late of Center Township, Butler County, Pennsylvania, Deceased.¶ Letters Testamentary upon the above-named estate having been granted to the undersigned, at File No. 10-26-0421, all persons having claims against the same will present them for payment, duly authenticated; and those indebted thereto, will please make immediate payment to:DYLAN L. BEACHEM,Executor448 Mahood RoadButler, PA 16001Bradley S. Kriley,EsquireS.R. LAW, LLC631 Kelly BoulevardP.O. Box 67Slippery Rock, PA16057